Terms & Conditions

Effective Date: July 2026

Welcome to Torwood Interiors

These Terms & Conditions govern your use of the Torwood Interiors website and the services we provide. By accessing our website or engaging our services, you agree to these terms.

Our Services

Torwood Interiors provides residential building and renovation services, including but not limited to:

Property Refurbishment
House Extensions
Loft Conversions
Property Maintenance
Joinery
Interior and Exterior Improvements

All services are subject to written quotations, project specifications, and mutual agreement.

Quotations

All quotations provided are:

Based on the information available at the time.
Valid for the period stated in the quotation.
Subject to change if project specifications or site conditions change.

Additional work requested after acceptance may incur additional charges.

Project Timelines

Estimated completion dates are provided in good faith.

Construction schedules may be affected by factors outside our control, including:

Severe weather
Material availability
Supplier delays
Planning approvals
Structural discoveries
Client-requested changes

We will keep clients informed of any significant delays.

Payments

Payment schedules will be outlined in your quotation or contract.

Invoices should be paid within the agreed payment terms.

Late payments may result in:

Suspension of work
Additional charges where permitted by law
Recovery of outstanding balances

Client Responsibilities

Clients agree to:

Provide accurate project information.
Allow reasonable access to the property.
Obtain any permissions not specifically agreed for us to arrange.
Review and approve quotations before work begins.
Make payments in accordance with agreed terms.

Variations

Any changes requested after work has commenced may affect:

Project cost
Completion date
Materials used
Labour requirements

All variations will be discussed and confirmed before additional work proceeds where practical.

Website Content

All content on this website, including text, graphics, logos, photographs, designs, and other materials, is the property of Torwood Interiors unless otherwise stated.

No content may be copied, reproduced, or distributed without prior written permission.

Limitation of Liability

While we make every effort to ensure the accuracy of information on this website, we cannot guarantee that all content will always be complete, current, or error-free.

To the fullest extent permitted by law, Torwood Interiors shall not be liable for indirect or consequential losses arising from the use of this website or our services.

Nothing in these Terms excludes liability that cannot legally be excluded under applicable law.

Third-Party Websites

Our website may include links to external websites for your convenience. We do not control or endorse the content or practices of these third-party websites.

Privacy

Your use of this website is also governed by our Privacy Policy.

Changes to These Terms

We reserve the right to update these Terms & Conditions at any time. Updated versions will be published on this page.

Governing Law

These Terms & Conditions are governed by the laws of England and Wales. Any disputes arising from these terms shall be subject to the exclusive jurisdiction of the courts of England and Wales.